IRONSIDE RURAL ROAD DISTRICT MEETING
The Ironside Rural Road District #5 has regular monthly meetings the second Tuesday of every month at the road shop building starting at 5 p.m.
Publish date: October 2, 2019
NOTICE IS HEREBY GIVEN
according to ORS 294.250(5), that the Malheur County Court Proceedings and the Schedule of Payments exceeding $500 will be posted and available for review at the Malheur County Courthouse (Clerk’s Office), the Ontario Community library, the Nyssa city public library, the Vale city public library, and the Jordan Valley U.S. Postal Service office. Copies of all or part of the posted information may be obtained upon request and upon payment of a fee not exceeding the actual cost incurred by the county in making copies of the posted information, from the Malheur County Clerk, 251 B Street West, Vale, OR 97918 or phone (541) 473-5151.
/s/Gayle V. Trotter
Malheur County Clerk
Publish date: October 2, 2019
THE BOISE LAW FIRM PLLC
R. AARON MORRISS #7722
RAYMOND D. SCHILD #3937
410 S. Orchard Street #184
Boise, Idaho 83705
Telephone: (986) 200-8865
Facsimile: (208) 485 8472 firstname.lastname@example.org
IN THE DISTRICT COURT OF THE THIRD JUDICIAL DISTRICT OF
THE STATE OF IDAHO, IN AND FOR THE COUNTY OF CANYON
Case No. CV-14-19-5743
SUMMONS AND NOTICE OF HEARING
In the Matter of the Termination of Parental Rights and Adoption by Stepparent of ERIKA JEAN TOOMBS D.O.B. July 13, 2011, A Minor Child.
NOTICE: YOU HAVE BEEN SUED IN THE ABOVE-ENTITLED MATTER. THE COURT MAY ENTER JUDGMENT AGAINST YOU WITHOUT FURTHER NOTICE UNLESS YOU RESPOND. READ THE INFORMATION BELOW.
TO: BRETT TOOMBS
NOTICE IS HEREBY GIVEN that a Petition for the termination of parental rights and step-parent adoption has been filed under and pursuant to Chapter 20, Title 16, Idaho Code praying for the termination of the parent/child relationship between BRETT TOOMBS and ERIKA JEAN TOOMBS and adoption by the minor child’s step-parent; JEREMIAH BENKSTEIN.
A copy of the Petition for Termination of Parental Rights and An Adoption By Step-Parent can be obtained from the law firm noted above or by request to the clerk of the Judge also noted above.
In order to defend this lawsuit, an appropriate written response must be filed with the above designated Court within 20 days of the final publication of this Summons and Notice. If you fail to so respond the Court may enter a Judgment Termination of Parental Rights without further proceedings.
YOU ARE FURTHER NOTIFIED That you are entitled to be represented by an attorney of your own choosing, and if counsel is requested and you are financially unable to employ counsel, counsel shall be appointed by the Court. You must notify the Clerk of the Honorable Judge assigned to this case, by telephoning (208) 454-7300 to request an appropriate application for such Court appointed attorney.
You are hereby notified of the existence of the Idaho Voluntary Adoption Registry maintained by the Vital Statistics Department of the Idaho Department of Health and Welfare as established by Idaho Code §39-259A.
Publish Date: September 11, 18, and 25, 2019 & October 2, 2019
Oregon Telephone Corporation – MTE
Oregon Telephone Corporation-MTE is a telecommunications provider who provides basic and enhanced services within its service territory. Oregon Telephone Corporation-MTE is an Eligible Telecommunications Carrier and as such, receives support from the Federal Universal Service Fund. Local service charges are as follows:
Single Party Residence Service $ 14.35 $ 16.60
Single Party Business Service $ 19.00 $ 19.00
State Mandated Emergency 911 Services
Each Telephone Number $ .75 $ .75
Federal Mandated Subscriber Line Charge
Each Single Line Residence &
Business Telephone Number $ 6.50 $ 6.50
Each Business Multi-Line &
Pay Telephone Number $ 9.20 $ 9.20
Customers of basic service have access to the public switched network, minutes of use for local service provided at no additional charge and access to emergency 911 services. Toll limitation services are also available for qualifying low-income customers. Lifeline service is available for qualifying low-income customers. The $9.25 federal Lifeline benefit may be applied to either qualifying voice services or qualifying broadband services.
Broadband internet access service is available at the following speeds and rates:
· 15 MBPS – $59.95
· 30 MBPS - $69.95
· 50 MBPS – 79.95
· 100 MBPS - $89.95
· 150 MBPS - $99.95
· 500 MBPS - $139.95
· 1 GIG - $239.95
Publish Date: October 2, 2019
STATEMENT OF NONDISCRIMINATION
Oregon Telephone Corporation is the recipient of Federal financial assistance from the U.S. Department of Agriculture, and is subject to the provisions of Title VI of the Civil Rights Act of 1964, as amended, Section 504 of the Rehabilitation Act of 1973, as amended, the Age Discrimination Act of 1975, as amended, and the rules and regulations of the U.S. Department of Agriculture.
In accordance with Federal civil rights law and the U.S. Department of Agriculture (USDA) civil rights regulations and policies, the USDA, its Agencies, offices, and employees, and institutions participating in or administering USDA programs are prohibited from discriminating based on race, color, national origin, religion, sex, gender identity (including gender expression), sexual orientation, disability, age, marital status, family/parental status, income derived from a public assistance program, political beliefs, or reprisal or retaliation for prior civil rights activity, in any program or activity conducted or funded by USDA (not all bases apply to all programs). Remedies and complaint filing deadlines vary by program or incident.
Persons with disabilities who require alternative means of communication for program information (e.g., Braille, large print, audiotape, American Sign Language, etc.) should contact the responsible Agency or USDA’s TARGET Center at (202) 720-2600 (voice and TTY) or contact USDA through the Federal Relay Service at (800) 877-8339. Additionally, program information may be made available in languages other than English.
To file a program discrimination complaint, complete the USDA Program Discrimination Complaint Form, AD-3027, found online at http://www.ascr.usda.gov/complaint_filing_cust.html and at any USDA office or write a letter addressed to USDA and provide in the letter all of the information requested in the form. To request a copy of the complaint form, call (866) 632-9992. Submit your completed form or letter to USDA by:
1. Mail: U.S. Department of Agriculture
Office of the Assistant Secretary for Civil Rights
1400 Independence Avenue, SW
Washington, D.C. 20250-9410
2. Fax: (202) 690-7442; or
3. Email: email@example.com.
USDA is an equal opportunity provider, employer, and lender.
The person responsible for coordinating this organization’s nondiscrimination compliance efforts is Delinda Kluser, General Manager. Any individual or specific class of individuals, who feel that this organization has subjected them to discrimination, may obtain additional information on the above statutes and regulations from USDA.
Publish Date: October 2, 2019
NOTICE OF PUBLIC IMPROVEMENT
Invitation to Bid (ITB)
Treasure Valley Community College
Career & Technical Education Center Project
The purpose of the ITB is to establish a Construction Contract for Career & Technical Education Center at Treasure Valley Community College. The Work under this Contract includes all labor, materials, transportation, equipment and services for, and incidental to, the completion of all construction Work in connection with the project described in the Contract Documents.
Sealed bids will be received by Treasure Valley Community College, 650 College Boulevard, Ontario, Oregon 97914, until 2:00 p.m., Mountain Standard Time, on Tuesday, November 12, 2019, for the above project located on the campus in Ontario, Oregon. Sealed bids will be received by Bernie Babcock at Treasure Valley Community College, 650 College Boulevard, Ontario, OR, 97914. Hand delivered sealed bids will be received by Bernie Babcock in the Science Building, College Board Room, at Treasure Valley Community College from 1:00 p.m. until 2:00 p.m., Mountain Standard Time, on Tuesday, November 12, 2019.
Bids will be publicly opened at 4:00 p.m. Mountain Standard Time, Tuesday, November 12, 2019, at the Science Building, College Board Room, in order to allow bidders the two-hour statutory period in which to submit the First-Tier Subcontractor Disclosure Form after the above stated bid submittal deadline.
Bids will be opened publicly at the above stated time and place and read aloud. Bids received after the time fixed for receiving Bids, cannot be considered. Bidders and other properly interested persons are invited to be present at the Bid Opening, but are not required.
TVCC may reject all Offers for good cause upon its finding that it is in the public interest to do so and may reject a particular Offer for any of the reasons listed under OAR 125-249-0440.
This project is for a Public Improvement and is subject to ORS 279C.800 to 279C.870.
VOLUNTARY PRE-BID CONFERENCE:
A pre-bid conference will be held on Tuesday, October 22, 2019 at 2:00 p.m., (MST), located at Vo-Tech Building, TVCC.
Any statements made at this conference will not change the Plans, Specifications or other Contract Documents unless an Addendum has been issued from TVCC and advertised on the ORPIN System.
BIDDERS ARE NOT REQUIRED TO ATTEND THIS VOLUNTARY PRE-BID CONFERENCE, BUT WITH THE COMPLEXITY OF THIS PROJECT IT IS STRONGLY RECOMMENDED THAT BIDDERS OR THEIR REPRESENTATIVE ATTEND.
The following range is a project estimate for bonding purposes: $6 – 6.5 million.
FUNDS FOR THIS PROJECT TVCC REVENUE, STATE OF OREGON MATCHING FUNDS AND FEDERAL EDA GRANT. THIS PROJECT WILL BE PARITIALLY FUNDED WITH FEDERAL FUNDS FROM THE UNITED STATES DEPARTMENT OF COMMERCE, ECONOMIC DEVELOPMENT ADMISTRATION AND THEREFORE IS SUBJECT TO THE FEDERAL LAWS AND REGULATIONS ASSOCIATED WITH THAT PROGRAM.
PROJECT COMPLETION DATES:
PROJECT START DATE: 10 calendar days from issuance of Notice to Proceed.
SUBSTANTIAL COMPLETION: 365 calendar days from issuance of Notice to Proceed.
FINAL COMPLETION: 396 calendar days from issuance of Notice to Proceed.
Liquidated damages will not apply to the contract resulting from this ITB.
Construction of a single story addition and remodel of the existing Vo-Tech building for the Career & Technical Education Center (CTE) on the Treasure Valley Community College (TVCC) Campus in Ontario, Oregon. The building is Type III-B Construction with Occupancy Types F-1 and B. The total building and fire area which includes mechanical mezzanine is 26,955 square feet. The addition building area is 12,015 square feet. The scope of the work includes:
Demolition of vertical circulation including elevator, walls and floors. Remodel existing toilet rooms. New interior and exterior paint. New TPO roof. New mechanical and ventilation system including air filtration system for welding. New 408 – 3 Phase power brought into building but not distributed. New LED light fixtures. New Fire Alarm and Data/Comm. New photo-voltaic system mounted to existing material storage canopy with minor structural upgrades. Existing fire sprinkler system will be revised per new layout with a new, pre-action system installed over existing material storage canopy.
Addition – New concrete foundation slab on grade. Steel column and open-web steel joist with metal deck. Exterior walls are primarily metal stud with rigid insulation and metal panels. Exterior windows are aluminum storefront. Roof is TPO. Interior walls are metal with painted gypsum board. Scope also includes hollow metal frames and doors, flush wood doors and associated hardware. Finishes include carpet, porcelain tile, acoustical ceiling tile and paint. Systems include fire protection, plumbing, mechanical, electrical, communications and security. Sitework includes earthwork, utilities, plantings and paving.
POINT OF CONTACT:
The single contact point for questions regarding the ITB, forms, Specifications, Plans, bidding process, change, clarification, the award process, protests and any other issues that may arise, is Amy Lindgren, PA, CTA, Inc. 800 W. Main St. Suite 800, Boise, ID 83702 at (208) 336-4900 and e-mail firstname.lastname@example.org.
The contact point for requests for brand approval, or substitution requests is Amy Lindgren, PA, CTA, Inc. 800 W. Main St. Suite 800, Boise, ID 83702 at (208) 336-4900 and e-mail email@example.com.
Offerors without access to the ORPIN System may download copies at a Plan Center.
Central Oregon Builders Exchange, 1902 NE 4th St. Bend, OR. 97701
Daily Journal of Commerce Plan Center, 921 SW Washington St., Ste. 210 Portland, OR 97205
Hermiston Plan Center, 1565 N. 1st Street, Suite 8A, Hermiston, OR 97838
McGraw Hill Construction Dodge, 3461 NW Yeon, Portland, OR 97210
OAME, 4134 N. Vancouver Ave Portland, OR 97217
Oregon Contractor Plan Center, 14625 E 82nd Dr. 212, Clackamas, OR 97015
Idaho AGC, 1649 W. Shoreline Dr., Ste. 100, Boise, ID 83702
Blueprint Specialties, 6205 W Overland Rd, Boise, ID 83709
Publish Dates: October 2, 9, 16, and 23, 2019
TRUSTEE’S NOTICE OF SALE TS No.: 085795-OR Loan No.: ******361F Reference is made to that certain trust deed (the “Deed of Trust”) executed by ENRIQUE MENDOZA, A MARRIED MAN, AS HIS SOLE AND SEPARATE PROPERTY, as Grantor, to NORTHWEST TRUSTEE SERVICES, as Trustee, in favor of MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC., AS DESIGNATED NOMINEE FOR GUILD MORTGAGE COMPANY, A CALIFORNIA CORPORATION, BENEFICIARY OF THE SECURITY INSTRUMENT, ITS SUCCESSORS AND ASSIGNS., as Beneficiary, dated 3/23/2012, recorded 3/29/2012, as Instrument No. 2012-1071, in the Official Records of Malheur County, Oregon, which covers the following described real property situated in Malheur County, Oregon: LAND IN THE ORIGINAL TOWNSITE, CITY OF ONTARIO, MALHEUR COUNTY, OREGON, ACCORDING TO THE OFFICIAL PLAT THEREOF, AS FOLLOWS: IN BLOCK 27: LOT(S) 13 AND 14. APN: 2194 // 18S4709AA 11800 Commonly known as: 631 SW 1ST ST ONTARIO OR 97914 The current beneficiary is: GUILD MORTGAGE COMPANY, A CALIFORNIA CORPORATION Both the beneficiary and the trustee have elected to sell the above-described real property to satisfy the obligations secured by the Deed of Trust and notice has been recorded pursuant to ORS 86.752(3). The default for which the foreclosure is made is the grantor’s failure to pay when due, the following sums:
Dates: No. Amount Total:
05/01/19 thru 09/01/19 5 $732.39 $3,661.95
Late Charges: $624.88
Beneficiary Advances: $0.00
Total Required to Reinstate: $4,286.83
TOTAL REQUIRED TO PAYOFF: $88,071.04
By reason of the default, the beneficiary has declared all obligations secured by the Deed of Trust immediately due and payable, including: the principal sum of $85,630.73 together with interest thereon at the rate of 3.875 % per annum, from 4/1/2019 until paid, plus all accrued late charges, and all trustee’s fees, foreclosure costs, and any sums advanced by the beneficiary pursuant to the terms and conditions of the Deed of Trust Whereof, notice hereby is given that the undersigned trustee, CLEAR RECON CORP, whose address is 111 SW Columbia Street #950, Portland, OR 97201, will on 1/22/2020, at the hour of 11:00 AM, standard time, as established by ORS 187.110, AT THE MAIN ENTRANCE TO THE MALHEUR COUNTY COURTHOUSE, 251 “B” STREET WEST, VALE, OR 97918, sell at public auction to the highest bidder in the form of cash equivalent (certified funds or cashier’s check) the interest in the above-described real property which the grantor had or had power to convey at the time it executed the Deed of Trust, together with any interest which the grantor or his successors in interest acquired after the execution of the Deed of Trust, to satisfy the foregoing obligations thereby secured and the costs and expenses of sale, including a reasonable charge by the trustee. Notice is further given that any person named in ORS 86.778 has the right to have the foreclosure proceeding dismissed and the Deed of Trust reinstated by payment to the beneficiary of the entire amount then due (other than the portion of principal that would not then be due had no default occurred), together with the costs, trustee’s and attorneys’ fees, and curing any other default complained of in the Notice of Default by tendering the performance required under the Deed of Trust at any time not later than five days before the date last set for sale. Without limiting the trustee’s disclaimer of representations or warranties, Oregon law requires the trustee to state in this notice that some residential property sold at a trustee’s sale may have been used in manufacturing methamphetamines, the chemical components of which are known to be toxic. Prospective purchasers of residential property should be aware of this potential danger before deciding to place a bid for this property at the trustee’s sale. In construing this notice, the masculine gender includes the feminine and the neuter, the singular includes plural, the word “grantor” includes any successor in interest to the grantor as well as any other persons owing an obligation, the performance of which is secured by the Deed of Trust, the words “trustee” and ‘beneficiary” include their respective successors in interest, if any. Dated: 9/9/2019 CLEAR RECON CORP 111 SW Columbia Street #950 Portland, OR 97201 Phone: 858-750-7600 866-931-0036 Shella Domilos, Authorized Signatory of Trustee
Publish Dates: October 2, 9, 16, and 23, 2019